Terms & Conditions
Welcome to the website of Eiffel Energy Technical Services. By accessing or using our website or services, you agree to the following terms and conditions. Please read them carefully.
1. Use of Website and Services
This website is intended to provide information about our interior design and fit‑out services. You agree to use this website only for lawful purposes and in accordance with applicable laws and regulations in the United Arab Emirates. You must not use the website to transmit or distribute harmful, illegal, or misleading content.
2. Scope of Services
Eiffel Energy Technical Services provides interior design, fit‑out, joinery, and related technical services. All project details, timelines, and costs are subject to written agreements, quotations, or contracts between the company and the client. Any design concepts, drawings, or documents remain the property of the company until full payment is received, unless otherwise agreed in writing.
3. Authority Approvals and Compliance
Certain projects may require approvals from Dubai authorities (such as municipalities, developers, or regulatory bodies). The client is responsible for providing accurate information and required documents for approvals. While we assist with submission and coordination, approval timelines depend on the relevant authorities and are not fully under our control.
4. Intellectual Property
All content on this website—including text, images, designs, logos, and graphics—is the property of Eiffel Energy Technical Services unless otherwise stated. You may not copy, reproduce, distribute, or modify any content without prior written permission.
5. Quotations and Payments
All quotations are valid for the period specified in the proposal. Payment terms, milestones, and conditions will be clearly stated in the project agreement or invoice. Delays in payment may result in project delays, suspension of work, or additional charges as per the agreement.
6. Project Changes and Variations
Any changes to the agreed scope of work must be approved in writing. Additional work or design changes may result in revised costs and timelines. Variation orders will be issued for any scope modifications.
7. Limitation of Liability
Eiffel Energy Technical Services shall not be liable for indirect, incidental, or consequential damages arising from the use of this website or services. Project‑related liabilities are governed by the signed contract or agreement with the client.
8. Service Disclaimer
While we strive to deliver high‑quality interior solutions, final results may vary based on site conditions, materials, authority requirements, and other external factors. All services are provided in accordance with agreed specifications and industry standards.
9. User Content
If you submit any content through the website (such as inquiries, images, or feedback), you grant us the right to use that information solely for business communication and service delivery.
10. Privacy
Your use of this website is also governed by our Privacy Policy. We handle personal information in accordance with applicable UAE data protection practices.
11. Changes to Terms
Eiffel Energy Technical Services reserves the right to update these Terms & Conditions at any time. Updated terms will be posted on this page, and continued use of the website constitutes acceptance of those changes.
12. Governing Law
These Terms & Conditions are governed by the laws of the United Arab Emirates. Any disputes shall be subject to the jurisdiction of the courts of Dubai, UAE.